Syfert Injury Law Firm

Your Trusted Partner in Personal Injury & Workers' Compensation

Call Now: 904-383-7448

2018 Georgia Code 9-3-50 | Car Wreck Lawyer

TITLE 9 CIVIL PRACTICE

Section 3. Limitations of Actions, 9-3-1 through 9-3-115.

ARTICLE 3 LIMITATIONS ON RECOVERY FOR DEFICIENCIES CONNECTED WITH IMPROVEMENTS TO REALTY AND RESULTING INJURIES

9-3-50. Definitions.

As used in this article, the term:

  1. "Person" means an individual, corporation, partnership, business trust, unincorporated organization, association, or joint-stock company.
  2. "Substantial completion" means the date when construction was sufficiently completed, in accordance with the contract as modified by any change order agreed to by the parties, so that the owner could occupy the project for the use for which it was intended.

(Ga. L. 1968, p. 127, §§ 5, 6.)

JUDICIAL DECISIONS

Substantial completion meant action time barred.

- Trial court erred in denying a developer's motion for summary judgment on the homeowners' claim for negligent construction because the developer presented testimony that the sale of the last townhouse closed on December 8, 2004, and that on the date of closing, construction of the townhouses was substantially complete; thus, O.C.G.A. § 9-3-51, the statute of repose, barred any action filed after December 8, 2012, and the homeowners filed the homeowners' suit two months after that date. Ashton Atlanta Residential, LLC v. Ajibola, 331 Ga. App. 231, 770 S.E.2d 311 (2015).

Cited in Turner v. Marable-Pirkle, Inc., 238 Ga. 517, 233 S.E.2d 773 (1977); Benning Constr. Co. v. Lakeshore Plaza Enters., Inc., 240 Ga. 426, 241 S.E.2d 184 (1977); Landon v. Williams Bros. Concrete Co., 149 Ga. App. 699, 256 S.E.2d 99 (1979); Standard Fire Ins. Co. v. Kent & Assocs., 232 Ga. App. 419, 501 S.E.2d 858 (1998); Colormatch Exteriors, Inc. v. Hickey, 275 Ga. 249, 569 S.E.2d 495 (2002); Wilks v. Overall Constr., Inc., 296 Ga. App. 410, 674 S.E.2d 320 (2009).

RESEARCH REFERENCES

Am. Jur. 2d.

- 13 Am. Jur. 2d, Building and Construction Contracts, § 115 et seq. 51 Am. Jur. 2d, Limitation of Actions, § 75.

C.J.S.

- 17B C.J.S., Contracts, § 589.

ALR.

- What constitutes "improvement to real property" for purposes of statute of repose or statute of limitations, 122 A.L.R.5th 1.

Cases Citing Georgia Code 9-3-50 From Courtlistener.com

Total Results: 2

Colormatch Exteriors, Inc. v. Hickey

Court: Supreme Court of Georgia | Date Filed: 2002-06-10

Citation: 569 S.E.2d 495, 275 Ga. 249, 2002 Fulton County D. Rep. 1795, 2002 Ga. LEXIS 479

Snippet: for the use for which it was intended." OCGA § 9-3-50(2). Utilization of this definition is logical,

Northbrook Excess & Surplus Insurance v. J. G. Wilson Corp.

Court: Supreme Court of Georgia | Date Filed: 1983-03-09

Citation: 300 S.E.2d 507, 250 Ga. 691, 1983 Ga. LEXIS 605

Snippet: architects' and contractors' immunity statute. OCGA § 9-3-50 et *692 seq. (Code Ann. § 3-1006 et seq.). There