C.F.R. » Title 48 » CHAPTER 1—FEDERAL ACQUISITION REGULATION › SUBCHAPTER G—CONTRACT MANAGEMENT › PART 42—CONTRACT ADMINISTRATION AND AUDIT SERVICES › Subpart 42.13—Suspension of Work, Stop-Work Orders, and Government Delay of Work

48 C.F.R. § 42.1305

42.1305 Contract clauses.

Read at: eCFRecfr.gov CornellLII GovInfogovinfo.gov CasesGoogle Scholar

(a) The contracting officer shall insert the clause at 52.242-14, Suspension of Work, in solicitations and contracts when a fixed-price construction or architect-engineer contract is contemplated.

(b)(1) The contracting officer may, when contracting by negotiation, insert the clause at 52.242-15, Stop-Work Order, in solicitations and contracts for supplies, services, or research and development.

(2) If a cost-reimbursement contract is contemplated, the contracting officer shall use the clause with its Alternate I.

(c) The contracting officer shall insert the clause at 52.242-17, Government Delay of Work, in solicitations and contracts when a fixed-price contract is contemplated for supplies other than commercial or modified-commercial products. The clause use is optional when a fixed-price contract is contemplated for services, or for supplies that are commercial or modified-commercial products.

[48 FR 42159, Sept. 19, 1983, as amended at 50 FR 2270, Jan. 15, 1985; 50 FR 25680, June 20, 1985. Redesignated and amended at 60 FR 48241, 48249, Sept. 18, 1995; 72 FR 27385, May 15, 2007; 86 FR 61030, Nov. 4, 2021]
Notes of Decisions
Cited in 3 cases, 2002–2005 · leading case: George Sollitt Constr. Co. v. United States, 64 Fed. Cl. 229 (Fed. Cl. 2005).
Sort: Relevance Newest Treatment
George Sollitt Constr. Co. v. United States, 64 Fed. Cl. 229 (Fed. Cl. 2005). “”); 48 C.F.R. § 42.1305 (a) (2004) ("The contracting officer shall insert the clause at 52.”
Fluor Enter., Inc. v. United States, 64 Fed. Cl. 461 (Fed. Cl. 2005). “, 48 C.F.R. § 42.1305 (referring to contract clauses to be included in fixed-price contracts for A & E services).”
Smelser v. United States, 53 Fed. Cl. 530 (Fed. Cl. 2002). “See 48 C.F.R. § 42.1305 . There are simply no provisions in the Agreement upon which Mr.”
Annotations are extracted automatically from the opinions in the Syfert caselaw corpus and ranked by authority, recency, and treatment. Dots show Syfertize treatment of the citing case itself.