(a) No action or arbitration, whether in contract, in tort, or otherwise, (1) to recover damages (A) for any deficiency in the design, planning, contract administration, supervision, observation of construction or construction of, or land surveying in connection with, an improvement to real property; (B) for injury to property, real or personal, arising out of any such deficiency; (C) for injury to the person or for wrongful death arising out of any such deficiency, or (2) for contribution or indemnity which is brought as a result of any such claim for damages shall be brought against any architect, professional engineer or land surveyor performing or furnishing the design, planning, supervision, observation of construction or construction of, or land surveying in connection with, such improvement more than seven years after substantial completion of such improvement.
(b) Notwithstanding the provisions of subsection (a) of this section, in the case of such an injury to property or the person or such an injury causing wrongful death, which injury occurred during the seventh year after such substantial completion, an action in tort to recover damages for such an injury or wrongful death may be brought within one year after the date on which such injury occurred, irrespective of the date of death, but in no event may such an action be brought more than eight years after the substantial completion of construction of such an improvement.
(c) For purposes of subsections (a) and (b) of this section, an improvement to real property shall be considered substantially complete when (1) it is first used by the owner or tenant thereof or (2) it is first available for use after having been completed in accordance with the contract or agreement covering the improvement, including any agreed changes to the contract or agreement, whichever occurs first.
(d) The limitation prescribed by this section shall not be asserted by way of defense by any person in actual possession or the control, as owner, tenant or otherwise, of such an improvement at the time any deficiency in such an improvement constitutes the proximate cause of the injury or death for which it is proposed to bring action.
(1969, P.A. 513, S. 1–5; 1972, P.A. 294, S. 36; P.A. 86-266, S. 2; P.A. 88-364, S. 70, 123; P.A. 98-137, S. 61, 62; 98-219, S. 33, 34.)
History: 1972 act removed actions and arbitrations brought against architectural designers from purview of section; P.A. 86-266 deleted former Subsec. (d), thereby expanding the applicability of the seven-year statute of limitations for actions against architects and engineers, relettering former Subsec. (e) accordingly; P.A. 88-364 made technical change in Subsec. (a); P.A. 98-137 made provisions applicable to actions and arbitrations against land surveyors for any deficiency in land surveying in connection with an improvement to property, effective October 1, 1998, and applicable to any action or arbitration brought on or after said date with respect to a land survey performed or furnished on or after said date; P.A. 98-219 revised effective date of P.A. 98-137, but without affecting this section.
Cited. 205 C. 219; Id., 741. Held constitutional. 207 C. 496. Cited. 214 C. 464. Where improvements to real property contemplated by architect's or engineer's services are not completed because of defect complained of, this section, and not Sec. 52-584, applies to plaintiff's cause of action. 247 C. 293. Doctrine of nullum tempus occurrit regi, i.e. no time runs against the king, exempts state from operation of section; Commissioner of Public Works had no authority to contractually waive repose period and such provision is unenforceable. 307 C. 412.
Statute intended to create a 7-year absolute maximum on actions against architects and engineers while leaving any other lesser limitations in place. 6 CA 212. Cited. 24 CA 81; 45 CA 775. Where forum was at issue, court properly declined to hear matter concerning statute of limitations re contract when it could not determine with positive assurance that issues of timeliness were intended by the parties to be excluded from the contract's arbitration clause. 62 CA 483. Section applies even though no physical alteration of real property is required or effected, and the seven year limitation period for bringing an action began to run when the alleged negligent design was completed. 181 CA 356.
Cited. 34 CS 22. Statutes of repose allow defendants at some point to be free from liability, absent unclean or fraudulent conduct, and logical conclusion is that legislature intended state to abide by statutes of repose. 51 CS 265.
Subsec. (a):
Statute not applicable to surveyors who performed or finished surveys before October 1, 1998. 72 CA 236.
Notes of Decisions
Cited in
27
cases, 1976–2018 · leading case:
Zapata v. Burns, 542 A.2d 700 (Conn. 1988).
Zapata v. Burns, 542 A.2d 700 (Conn. 1988).
· cites it 32× “The dispositive issue is the constitutionality, under both the state and federal constitutions, of General Statutes § 52-584a which bars actions against architects and engineers seven years after substantial completion of a project, irrespective of whether a claim has arisen by…”
Grigerik v. Sharpe, 721 A.2d 526 (Conn. 1998).
· cites it 39× “The dispositive issues in this certified appeal are: (1) whether the seven year limitation period of General Statutes § 52-584a, 1 or the two year limitation *295 period of General Statutes § 52-584, 2 2 applies to this action; and (2) whether it is the intent of the promisee of…”
R.A. Civitello Co. v. City of New Haven, 504 A.2d 542 (Conn. App. Ct. 1986).
· cites it 38× “It was also agreed that if the seven year statute of limitations covering architects and engineers; General Statutes § 52-584a; applied, the city’s claims would not be barred.”
Plato Assocs., LLC v. Env't Compliance Servs., Inc., 9 A.3d 698 (Conn. 2010).
· cites it 36× “Under General Statutes § 52-584a (a), 1 no action against an architect, professional engineer or land surveyor to recover damages for any defect in the design, planning or construction of an improvement to real property may be brought more than seven years after substantial…”
Coniglio v. White, 804 A.2d 990 (Conn. App. Ct. 2002).
· cites it 9× “to 1985) § 52-584a, a seven year statute of limitations applied to both the contract and negligence counts.”
Sandvig v. Dubreuil & Sons, Inc., 789 A.2d 1012 (Conn. App. Ct. 2002).
· cites it 5× “Next, she argues that General Statutes § 52-595, which concerns fraudulent concealment, tolls the statute of limitations during the entire period of concealment.”
Windsor v. Loureiro Eng'g Assocs., 186 A.3d 729 (Conn. App. Ct. 2018).
· cites it 17× “1 On appeal, the plaintiff claims that the court improperly discharged the jury and rendered judgment as a matter of law on the defendants' special defense asserting that the plaintiff's action was barred by the seven year statute of limitations set forth in General Statutes §…”
Verna v. Comm'r of Revenue Servs., 801 A.2d 769 (Conn. 2002).
· cites it 4× “2d 526 (1998), we defined the term “ ‘improvement to real property’ ” in the context of interpreting General Statutes § 52-584a. 9 In that case, we stated that “[t]he phrase ‘improvement to real property’ is a phrase that has acquired a particular meaning in the law.”
Greco v. United Tech. Corp., 890 A.2d 1269 (Conn. 2006).
· cites it 2× “property [damage]” actions [emphasis added]); General Statutes § 52-584a (a) (no action against an architect, professional engineer or land surveyor “[1] to recover damages [A] for any deficiency in the design, planning, contract administration, supervision, observation of…”
Barrett v. Montesano, 849 A.2d 839 (Conn. 2004).
· cites it 2× “ession or control of the product”); General Statutes § 52-577d (“[notwithstanding the provisions of section 52-577, no action to recover damages for personal injury to a minor, including emotional distress, caused by sexual abuse, sexual exploitation or sexual assault may be…”
Carlin Pozzi Architects, P.C. v. Town of Bethel, 767 A.2d 1272 (Conn. App. Ct. 2001).
· cites it 4× “The court then concluded that the issues raised by the plaintiff, including its defense that the statute of limitations, General Statutes § 52-584a, barred the defendant’s claims of defective performance of the plaintiffs contractual obligations, were within the scope of the…”
Ecker v. Town of West Hartford, 530 A.2d 1056 (Conn. 1987).
“The plaintiff further argues that the three year repose period in question, when compared to the periods of limitation for death actions under General Statutes § 52-577a 15 (ten years or longer for product liability *242 claims), § 52-584a 16 (seven years for action against an…”
Annotations are extracted automatically from the opinions in the
Syfert caselaw corpus and ranked by authority, recency, and
treatment. Dots show Syfertize treatment of the citing case itself.