28 U.S.C. § 1499
Liquidated damages withheld from contractors under chapter 37 of title 40
The United States Court of Federal Claims shall have jurisdiction to render judgment upon any claim for liquidated damages withheld from a contractor or subcontractor under section 3703 of title 40.
Notes of Decisions
Cited in 5
cases, 1962–1993 · leading case: Glidden Co. v. Zdanok, 370 U.S. 530 (1962).
Glidden Co. v. Zdanok, 370 U.S. 530 (1962). “[40] 28 U. S. C. § 1499 (violations of the Eight-Hour Law, 37 Stat.”
Shook v. United States, 26 Cl. Ct. 1477 (Ct. Cl. 1992). “Sections of 28 U.S.C. § 1499 (1982) 8 and 40 U.S.C.App.”
Inland Serv. Corp. v. United States, 231 Ct. Cl. 974 (Ct. Cl. 1982). “§ 330 (c); 28 U.S.C. § 1499 . Defendant moves for summary judgment on the grounds that the *975 decision of the Secretary of Labor is supported by substantial evidence and is not arbitrary or capricious.”
Cobra Constr. Co. v. United States, 14 Cl. Ct. 523 (Ct. Cl. 1988). “Judge Wood dismissed the complaint for lack of jurisdiction, pursuant to 28 U.S.C. § 1499 (1982), which establishes jurisdiction in this court to render judgment upon any claim for liquidated damages withheld from a contractor under the Act.”
Keene Corp. v. United States, 28 Fed. Cl. 2035 (Fed. Cir. 1993). “§ 1497 ; 28 U.S.C. § 1499 (granting jurisdiction to “render judgment” over other claims).”
Annotations are extracted automatically from the opinions in the
Syfert caselaw corpus and ranked by authority, recency, and
treatment. Dots show Syfertize treatment of the citing case itself.