Kentucky Revised Statutes

Ky. Rev. Stat. § 376.230 (2026)

Lien dissolved unless statement timely filed with county clerk -- Form and

✓ current as of May 2026

Find cases: SyfertCases citing this section KY-LRCapps.legislature.ky.gov JustiaChapter on Justia CornellLII Search CasesGoogle Scholar

content of statement -- Duties and fees of clerk. (1) The lien provided for in KRS 376.210 shall be dissolved unless the person who furnishes the labor, materials, or supplies shall, whichever is later, within sixty (60) days after the last day of the month in which any labor, materials, or supplies were furnished, or by the date of substantial completion, file in the county clerk's office of each county in which labor, materials, or supplies were furnished, except as hereinafter provided, a statement in writing verified by affidavit of the claimant or his or her authorized agent or attorney, setting forth the amount due for which the lien is claimed, the date on which labor, materials, or supplies were last furnished and the name of the canal, railroad, bridge, public highway, or other public improvement upon which it is claimed. (2) In all cases where a lien is claimed for labor, materials, or supplies furnished for the improvement of any bridge, public highway, or other public property owned by the state or by any county, charter county, urban-county, consolidated local government, or city, the statement of lien shall be filed only in the county clerk's office of the county in which the seat of government of the owner of the property is located. (3) The county clerk, upon the filing of the statement, shall make an abstract and entry thereof as now provided by law in case of mechanics' liens in the same book used for that purpose, and shall make proper index thereof. The clerk shall be paid by the party filing the claim, and for attesting any copy of the lien statement. If he or she is required to make the copy, he or she may make an additional charge as provided by law. The clerk's fees shall be determined pursuant to KRS 64.012. All of these charges may be recovered by the lien claimant as costs from the party and out of the fund against which the claim is filed. Effective: June 26, 2007 History: Amended 2007 Ky. Acts ch. 136, sec. 7, effective June 26, 2007. -- Amended 2005 Ky. Acts ch. 104, sec. 1, effective June 20, 2005. -- Amended 1978 Ky. Acts ch. 84, sec. 14, effective June 17, 1978. -- Amended 1972 Ky. Acts ch. 296, sec. 1. -- Recodified 1942 Ky. Acts ch. 208, sec. 1, effective October 1, 1942, from Ky. Stat. sec. 2494.

Notes of Decisions

Cited in 4 cases, 1972–1988 · leading case: Allgeier & Dyer, Inc. v. City of Bowling Green (In Re Allgeier & Dyer, Inc.), 18 B.R. 82 (Bankr. W.D. Ky. 1982).

Sort: Relevance Newest Treatment

Allgeier & Dyer, Inc. v. City of Bowling Green (In Re Allgeier & Dyer, Inc.), 18 B.R. 82 (Bankr. W.D. Ky. 1982). · cites it 3× “” KRS 376.230 provides in part: (1) The lien provided for in KRS 376.”

In Re D & B Elec., Inc., 4 B.R. 263 (Bankr. W.D. Ky. 1980). · cites it 2× “Upon the foregoing reasoning and authority, IT IS ORDERED that Rueff Lighting Company’s claim be upheld.”

Wehr Constructors, Inc. v. Steel Fabricators, Inc., 769 S.W.2d 51 (Ky. Ct. App. 1988). · cites it 2× “210, KRS 376.230 and KRS 376.240. J & D, Vulcraft and Wehr sought entry of summary judgment and on September 30, 1986, the trial court granted Wehr’s motion, based on the fact that J & D and Vulcraft had not filed their lien on the public project within 30 days of the last day…”

Sandusky Foundry & Mach. Co. v. City of Wickliffe, 369 F. Supp. 439 (W.D. Ky. 1972). · cites it 4× “250(2) provides that unless the contractor within thirty days from date of delivery of an attested copy of the statement of lien required by KRS 376.230 files with the public authority a written protest as to the correctness of the amount due the lien claimant or the liability…”

— Ky. Rev. Stat. § 376.230(1) — 2 cases

Wehr Constructors, Inc. v. Steel Fabricators, Inc., 769 S.W.2d 51 (Ky. Ct. App. 1988). “210, KRS 376.230 and KRS 376.240. J & D, Vulcraft and Wehr sought entry of summary judgment and on September 30, 1986, the trial court granted Wehr’s motion, based on the fact that J & D and Vulcraft had not filed their lien on the public project within 30 days of the last day…”

Sandusky Foundry & Mach. Co. v. City of Wickliffe, 369 F. Supp. 439 (W.D. Ky. 1972). “250(2) provides that unless the contractor within thirty days from date of delivery of an attested copy of the statement of lien required by KRS 376.230 files with the public authority a written protest as to the correctness of the amount due the lien claimant or the liability…”

— Ky. Rev. Stat. § 376.230(2) — 1 case

Annotations are extracted automatically from the opinions in the Syfert caselaw corpus and ranked by authority, recency, and treatment. Dots show Syfertize treatment of the citing case itself.